rate contract for horizontal connectivity work including supply, installation and commissioning of last miles equipment on turnkey basis for government offices in the state of gujarat
The tender document is a Request for Proposal (RFP) for selecting a bidder for the Design build finance operate and transfer of cement grinding units. It outlines the terms and conditions for a long-term agreement to construct and operate a cement grinding unit on a Design, Build, Finance, Operate, and Transfer (DBFOT) basis.
Agreement Duration : The agreement is valid for 30 years from the Scheduled Commercial Operation Date (SCOD).
Grant of Concession : The Owner grants the Concessionaire the right to access the project land and perform the scope of work.
Scope of Work : Includes designing, financing, construction, commissioning, stabilization, manufacturing of cement, operation and maintenance of project assets, and packaging and delivery of cement.
Raw Materials and Utilities : The Owner is responsible for providing raw materials and electricity.
Obligations of Concessionaire : Compliance with all applicable laws, maintaining safety standards, and ensuring the project assets meet performance parameters.
Commissioning and Stabilization : Detailed timelines and conditions for commissioning and stabilizing the grinding unit.
Conversion Charges : Payment terms for the conversion charges based on the lowest cost bid accepted by the Owner.
Liquidated Damages : Provisions for delay liquidated damages and shortfall liquidated damages.
Termination : Conditions under which the agreement can be terminated by either party and the consequences of termination.
Dispute Resolution : Any disputes arising under the agreement shall be resolved through arbitration.
Specifications and Standards : As per Ambuja standards
Annual Contracted Quantity of Cement
KPIs of Cement : Key KPIs of cement to be maintained
This document provides a comprehensive framework for the Concessionaire to develop and operate the cement grinding unit, ensuring compliance with all legal, technical, and operational requirements.
Eligibility Criteria - Download